Skip to content
Constructeams
SAM.govCloses in 7 days

Design-Bid-Build (DBB) SOF Marine Raider Facilities Complex, Marine Corps Base (MCB) Camp Lejeune, North Carolina

Location
Camp Lejeune, United States
Responses due
Oct 15, 2026

Overview

The general intent of this solicitation is to award a Fixed Price Construction Contract for a Design-Bid-Build (DBB), construction services for the P-1550 SOF Marine Raider Battalion Company & Team Facilities located at the Marine Corps Base in Camp Lejeune in North Carolina. The project is to provide construction of 6,815 SM (73,400 SF) SOF Marine Battalion Operations, Supply, Communications, and Intel facility; 11,812 SM (127,200 SF) Company HQ and Team Facilities; 1,635 SM (17,600 SF) Company Storage Buildings and miscellaneous supporting structures, utilities, parking, roadways, pedestrian ways/sidewalks, and site work at Stone Bay at the Marine Corps Base (MCB) in Camp Lejeune, North Carolina. The structures will be single-story steel frame buildings with brick veneer over metal studs, standing seam metal roofs, metal soffits, and translucent wall panels. Special construction features include pile foundations, surcharged sites, wetlands mitigation, and storm water best management practices.

Source: SAM.govView in Constructeams

Similar open bids

SAM.govCloses tomorrow

FCC BUTNER - WATER CHEMICAL TESTING AND CONSULTATION SERVICES

Modificaiton 1 - The Government has issued a modification to this solicitation. FCC Butner host an onsite visit on September 21, 2026 at 9:00 AM EST, to allow vendors to review the facility and fully understand the requirements. Interested parties will report to the FCC Butner Training Center, located at Old Highway 75, Butner, NC 27509. Please see attached Site Visit Memo and NCIC Background Check form; all parties interested in attending this site visit submitt the background check form submitted by noon EST on September 16, 2026. Vendors may collect one water sample up to a maximum of 250 mL from a designated location. Samples must be placed in approved sealed containers, collected under staff supervision, and removed from the institution the same day. No large containers, multiple samples, or on?site testing are permitted. To ensure adequate time to prepare quotes, the solicitation closing date is being extended to October 9, 2026. No other changes are being made to the solicitation. __________________________________________________________________________ This is a combined synopsis/solicitation for the Water Chemical Testing and Consultation Services for the Federal Correctional Complex Butner, prepared in accordance with FAR Part 12. This announcement constitutes the only solicitation. Offers are being requested and a separate written solicitation will not be issued. The Federal Bureau of Prisons (FBOP), Field Acquisition Office (FAO), intends to award an indefinite deliver/requirements type contract with firm-fixed unit pricing. The award will be based on price and past performance. The contract periods for the service will consist of a base year with four, 12-month option years, at the unilateral discretion of the Government. Solicitation number 15BGCS26Q10600001 is issued as a Request for Quotation (RFQ) to any interested party (unrestricted procurement. The North American Industrial Classification (NAICS) code is 325998 with a small business size standard of 650 employees. The solicitation document (RFQ), located in the Attachments/Links section, contains the Statement of Work (SOW), of which provides a detailed description of the requirement(s) of the items to be acquired, a list of line-item number(s) and items, quantities and units of measure (including option(s), if applicable). The solicitation document incorporates most provisions and clauses by reference. The full text of provisions and clauses my be accessed electronically at www.acquisition.gov. Quotations shall be completed, utilizing the attached Standard Form 1449 and any additional required forms per the quote submission instructions. Quotes shall be submitted, on or before the solicitation deadline Specified in Block 8 of the Standard Form 1449, via email, to Justin Wray at jwray@bop.gov. Section L of the solicitation document provides detailed quote submission instructions, evaluation and award methodology information and any specific documentation requirements to be submitted along with the quote. THIS IS A NOT A NEW REQUIREMENT - Services are currently in place for this requirement under a yearly Purchase Order. The current incumbent is Venergy Group, LLC. All future information concerning this acquisition, including solicitation amendments/RFQ changes, will be distributed solely through this platform. Interested parties are responsible for monitoring this site, during the entire solicitation period, to ensure you have the most up-to-date information about this acquisition. Failure to provide all quotation requirements on most up to date RFQ may result in your quote being eliminated from consideration for award. Hard copies of the solicitation will not be available. The website provides all downloading instructions to obtain a copy of the solicitation. All contractors doing business with the Federal Government are advised that this future solicitation includes the provision at FAR 52.204-7, System for Award Management (SAM); of this provision requires all contractors doing business with the federal government to be registered in the SAM database at www.sam.gov. Contractors shall include their Unique Entity Identification Number (UEI) number in their offers. The Contracting Officer will verify registration in the System for Award Management (SAM) database prior to award by entering the potential awardees UEI number into the SAM database. Failure to complete the registration procedures outlined in provision may result in elimination from consideration for award. If you have questions regarding the System for Award Management (SAM), Government procurements in general, or need assistance in the preparation of your quote, the APEX Accelerators program may be able to help. The APEX Accelerators was authorized by Congress in 1985 to expand the number of businesses capable of participating in government contracts. To locate a APEX Accelerator near you, go to https://www.apexaccelerators.us/#/contact Contractors must comply with FAR 52.222-54, E-Verify Requirements, by enrolling in EVerify within 30 days of contract award and beginning verification within 90 days of enrollment.

Butner
Due Oct 9, 2026View bid
SAM.govCloses tomorrow

FCC BUTNER - WATER CHEMICAL TESTING AND CONSULTATION SERVICES

Modificaiton 1 - The Government has issued a modification to this solicitation. FCC Butner host an onsite visit on September 21, 2026 at 9:00 AM EST, to allow vendors to review the facility and fully understand the requirements. Interested parties will report to the FCC Butner Training Center, located at Old Highway 75, Butner, NC 27509. Please see attached Site Visit Memo and NCIC Background Check form; all parties interested in attending this site visit submitt the background check form submitted by noon EST on September 16, 2026. To ensure adequate time to prepare quotes, the solicitation closing date is being extended to October 9, 2026. No other changes are being made to the solicitation. __________________________________________________________________________ This is a combined synopsis/solicitation for the Water Chemical Testing and Consultation Services for the Federal Correctional Complex Butner, prepared in accordance with FAR Part 12. This announcement constitutes the only solicitation. Offers are being requested and a separate written solicitation will not be issued. The Federal Bureau of Prisons (FBOP), Field Acquisition Office (FAO), intends to award an indefinite deliver/requirements type contract with firm-fixed unit pricing. The award will be based on price and past performance. The contract periods for the service will consist of a base year with four, 12-month option years, at the unilateral discretion of the Government. Solicitation number 15BGCS26Q10600001 is issued as a Request for Quotation (RFQ) to any interested party (unrestricted procurement. The North American Industrial Classification (NAICS) code is 325998 with a small business size standard of 650 employees. The solicitation document (RFQ), located in the Attachments/Links section, contains the Statement of Work (SOW), of which provides a detailed description of the requirement(s) of the items to be acquired, a list of line-item number(s) and items, quantities and units of measure (including option(s), if applicable). The solicitation document incorporates most provisions and clauses by reference. The full text of provisions and clauses my be accessed electronically at www.acquisition.gov. Quotations shall be completed, utilizing the attached Standard Form 1449 and any additional required forms per the quote submission instructions. Quotes shall be submitted, on or before the solicitation deadline Specified in Block 8 of the Standard Form 1449, via email, to Justin Wray at jwray@bop.gov. Section L of the solicitation document provides detailed quote submission instructions, evaluation and award methodology information and any specific documentation requirements to be submitted along with the quote. THIS IS A NOT A NEW REQUIREMENT - Services are currently in place for this requirement under a yearly Purchase Order. The current incumbent is Venergy Group, LLC. All future information concerning this acquisition, including solicitation amendments/RFQ changes, will be distributed solely through this platform. Interested parties are responsible for monitoring this site, during the entire solicitation period, to ensure you have the most up-to-date information about this acquisition. Failure to provide all quotation requirements on most up to date RFQ may result in your quote being eliminated from consideration for award. Hard copies of the solicitation will not be available. The website provides all downloading instructions to obtain a copy of the solicitation. All contractors doing business with the Federal Government are advised that this future solicitation includes the provision at FAR 52.204-7, System for Award Management (SAM); of this provision requires all contractors doing business with the federal government to be registered in the SAM database at www.sam.gov. Contractors shall include their Unique Entity Identification Number (UEI) number in their offers. The Contracting Officer will verify registration in the System for Award Management (SAM) database prior to award by entering the potential awardees UEI number into the SAM database. Failure to complete the registration procedures outlined in provision may result in elimination from consideration for award. If you have questions regarding the System for Award Management (SAM), Government procurements in general, or need assistance in the preparation of your quote, the APEX Accelerators program may be able to help. The APEX Accelerators was authorized by Congress in 1985 to expand the number of businesses capable of participating in government contracts. To locate a APEX Accelerator near you, go to https://www.apexaccelerators.us/#/contact Contractors must comply with FAR 52.222-54, E-Verify Requirements, by enrolling in EVerify within 30 days of contract award and beginning verification within 90 days of enrollment.

Butner
Due Oct 9, 2026View bid
SAM.govCloses tomorrow

FCC BUTNER - WATER CHEMICAL TESTING AND CONSULTATION SERVICES

Modificaiton 1 - The Government has issued a modification to this solicitation. FCC Butner host an onsite visit on September 21, 2026 at 9:00 AM EST, to allow vendors to review the facility and fully understand the requirements. Interested parties will report to the FCC Butner Training Center, located at Old Highway 75, Butner, NC 27509. Please see attached Site Visit Memo and NCIC Background Check form; all parties interested in attending this site visit submitt the background check form submitted by noon EST on September 16, 2026. Vendors may collect one water sample up to a maximum of 250 mL from a designated location. Samples must be placed in approved sealed containers, collected under staff supervision, and removed from the institution the same day. No large containers, multiple samples, or on?site testing are permitted. To ensure adequate time to prepare quotes, the solicitation closing date is being extended to October 9, 2026. No other changes are being made to the solicitation. __________________________________________________________________________ This is a combined synopsis/solicitation for the Water Chemical Testing and Consultation Services for the Federal Correctional Complex Butner, prepared in accordance with FAR Part 12. This announcement constitutes the only solicitation. Offers are being requested and a separate written solicitation will not be issued. The Federal Bureau of Prisons (FBOP), Field Acquisition Office (FAO), intends to award an indefinite deliver/requirements type contract with firm-fixed unit pricing. The award will be based on price and past performance. The contract periods for the service will consist of a base year with four, 12-month option years, at the unilateral discretion of the Government. Solicitation number 15BGCS26Q10600001 is issued as a Request for Quotation (RFQ) to any interested party (unrestricted procurement. The North American Industrial Classification (NAICS) code is 325998 with a small business size standard of 650 employees. The solicitation document (RFQ), located in the Attachments/Links section, contains the Statement of Work (SOW), of which provides a detailed description of the requirement(s) of the items to be acquired, a list of line-item number(s) and items, quantities and units of measure (including option(s), if applicable). The solicitation document incorporates most provisions and clauses by reference. The full text of provisions and clauses my be accessed electronically at www.acquisition.gov. Quotations shall be completed, utilizing the attached Standard Form 1449 and any additional required forms per the quote submission instructions. Quotes shall be submitted, on or before the solicitation deadline Specified in Block 8 of the Standard Form 1449, via email, to Justin Wray at jwray@bop.gov. Section L of the solicitation document provides detailed quote submission instructions, evaluation and award methodology information and any specific documentation requirements to be submitted along with the quote. THIS IS A NOT A NEW REQUIREMENT - Services are currently in place for this requirement under a yearly Purchase Order. The current incumbent is Venergy Group, LLC. All future information concerning this acquisition, including solicitation amendments/RFQ changes, will be distributed solely through this platform. Interested parties are responsible for monitoring this site, during the entire solicitation period, to ensure you have the most up-to-date information about this acquisition. Failure to provide all quotation requirements on most up to date RFQ may result in your quote being eliminated from consideration for award. Hard copies of the solicitation will not be available. The website provides all downloading instructions to obtain a copy of the solicitation. All contractors doing business with the Federal Government are advised that this future solicitation includes the provision at FAR 52.204-7, System for Award Management (SAM); of this provision requires all contractors doing business with the federal government to be registered in the SAM database at www.sam.gov. Contractors shall include their Unique Entity Identification Number (UEI) number in their offers. The Contracting Officer will verify registration in the System for Award Management (SAM) database prior to award by entering the potential awardees UEI number into the SAM database. Failure to complete the registration procedures outlined in provision may result in elimination from consideration for award. If you have questions regarding the System for Award Management (SAM), Government procurements in general, or need assistance in the preparation of your quote, the APEX Accelerators program may be able to help. The APEX Accelerators was authorized by Congress in 1985 to expand the number of businesses capable of participating in government contracts. To locate a APEX Accelerator near you, go to https://www.apexaccelerators.us/#/contact Contractors must comply with FAR 52.222-54, E-Verify Requirements, by enrolling in EVerify within 30 days of contract award and beginning verification within 90 days of enrollment.

Butner
Due Oct 9, 2026View bid
SAM.govCloses today

Bitterroot Front 10 Year G-Z IRSC

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Part 12. This announcement constitutes the only solicitation. Proposals are being requested and a separate written solicitation will not be issued. Solicitation number 12363N26R4014 is issued as a Request for Proposal (RFP) for the Bitterroot Front G-Z Long Term Integrated Resource Service Contract. The Bitterroot Front Project area spans roughly 145,000 acres across the Stevensville and Darby Ranger Districts, where dense, overstocked mixed?conifer stands and widespread tree mortality have increased susceptibility to insect outbreaks and extreme wildfire behavior. Following a decade of severe fires, the project aims to reduce wildfire risk to nearby communities and restore forest health through treatments such as thinning, harvesting, mechanical fuel reduction, and prescribed burning. These efforts focus on improving stand vigor, promoting fire?adapted species, reducing hazardous fuels, and enhancing safety and effectiveness for wildfire responders. A secondary objective of the long?term contract is to provide a consistent timber supply for local forest products industries, while contractors complete tasks including unit layout, timber cruising, road work, and timber removal as part of a broader strategy to increase the pace and scale of forest restoration. This acquisition is set-aside for small business concerns. The applicable North American Industry Classification Standard Code is 113310 and the small business size standard is 500 Employees This acquisition is a Total Small Business Set-Aside. All responsible sources may submit a quotation which will be considered by the agency. Proposals are to be submitted via email to Mark Phillipp at mark.phillipp@usda.gov and Matt Daigle at matthew.daigle@usda.gov.

United States
Due Oct 8, 2026View bid
SAM.govCloses today

Bitterroot Front 10 Year G-Z IRSC

8/3/2026- Replaces word versions of Attachements C04c_2a, C04d_3a and C04e_4a (Appendicies A-C) with PDFs. No other corrections. This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Part 12. This announcement constitutes the only solicitation. Proposals are being requested and a separate written solicitation will not be issued. Solicitation number 12363N26R4014 is issued as a Request for Proposal (RFP) for the Bitterroot Front G-Z Long Term Integrated Resource Service Contract. The Bitterroot Front Project area spans roughly 145,000 acres across the Stevensville and Darby Ranger Districts, where dense, overstocked mixed?conifer stands and widespread tree mortality have increased susceptibility to insect outbreaks and extreme wildfire behavior. Following a decade of severe fires, the project aims to reduce wildfire risk to nearby communities and restore forest health through treatments such as thinning, harvesting, mechanical fuel reduction, and prescribed burning. These efforts focus on improving stand vigor, promoting fire?adapted species, reducing hazardous fuels, and enhancing safety and effectiveness for wildfire responders. A secondary objective of the long?term contract is to provide a consistent timber supply for local forest products industries, while contractors complete tasks including unit layout, timber cruising, road work, and timber removal as part of a broader strategy to increase the pace and scale of forest restoration. This acquisition is set-aside for small business concerns. The applicable North American Industry Classification Standard Code is 113310 and the small business size standard is 500 Employees This acquisition is a Total Small Business Set-Aside. All responsible sources may submit a quotation which will be considered by the agency. Proposals are to be submitted via email to Mark Phillipp at mark.phillipp@usda.gov and Matt Daigle at matthew.daigle@usda.gov.

United States
Due Oct 8, 2026View bid
NYC City RecordCloses today

SMD_Services IDIQ Contract for Annual Cleaning and Inspection of Gravity Roof Tanks at Various NYCHA Buildings, Citywide

Scope of Work:  The annual inspection, cleaning and disinfection of roof tanks on NYCHA properties in compliance with all applicable New York City, New York State, and Federal regulations. at various developments citywide. All work shall comply with applicable laws, codes and standards, including but not limited to NYC Health Code §§ 141.07 & 141.09, Rules of the City of New York, Title 24, Chapter 31, NYC Administrative Code § 17-194, Plumbing Code §§ 606.5 / 606.5.4.3, NYS Sanitary Code, Part 5, ANSI/AWWA/APHA/WEF Industry Standards, Safe Drinking Water Act (SDWA), §28-301.1 of the NYC Construction Code, NYC Local Law 76, Occupational Safety and Health Administration (OSHA) as well as any other regulatory requirements that pertain to gravity water tanks (roof tanks) within the city of New York. Each tank shall be inspected, cleaned, disinfected and sampled for E.Coli and Total Coliform at a minimum annually during each one (1) year period of this contract. Tanks may be cleaned and sampled multiple times a year. Contract Term: 3 years from the award date on NYCHAs Purchase Order.  NYCHA, in its sole discretion, shall have the option to extend the Term of this Contract for up to 2 one-year renewals. Bid Security: 100% of Contract Minimum. Payment & Performance Bonds: 100% of Minimum. Labor Law 220i Public Work Registration Certificate/Certification: Pursuant to Article 8, Section 220-i of the New York State Labor Law. The Bidder and each subcontractor must be registered with the New York State Department of Labor. See https://dol.ny.gov/contractor-and-subcontractor-landing.  For additional information refer to the Important Bid Notice document attachment included in this RFQ.  This Solicitation is not subject to PLA. This solicitation does not require PQL. Section 3 Resident Economic Opportunity Plan: Section 3 Resident Economic Opportunity (REO) Plan must be submitted via eComply, https://nycha.ecomply.us/. Do not include Section 3 documentation within bid submission via iSupplier. For eComply log-in assistance contact eComply Tech support, support@ecomplysolutions.com. For Section 3 submission assistance contact NYCHAs SMP Vendor Support team at eComply.support@nycha.nyc.gov  Pre-Bid Conference: A non-mandatory, but strongly recommended, MS Teams Pre-bid Conference will be held on September 9, 2026, at 1:00 PM  To join us, please follow the instructions below: Option 1: Click the following link or copy, and paste and go it into a new web browser: https://teams.microsoft.com/meet/284356622821641?p=SIlxBEu2AMZmRVxu4a Meeting ID: 284 356 622 821 641 Passcode: fk9AV7Yt Option 2: Dial in by phone +1-646-838-1534 United States, New York City Phone conference ID: 638894668# RFQ Question Submission Deadline: September 16, 2026 Questions regarding this RFQ should be sent to the following email address: construction.procurement@nycha.nyc.gov. Question & Answer Release Date: September 23, 2026. Only questions regarding this RFQ submitted to construction.procurement@nycha.nyc.gov (include RFQ number in subject field) prior to Question Deadline will be accepted. In addition to the documents attached below, bidders are directed to review the Special Notices and Conditions, Instructions to Bidders, and General Conditions prior to submitting a bid.  To access these documents, click on the 'Contract Terms' tab above, and then 'Preview Contract Terms,' to download a PDF version. Prior to submitting a bid, confirm the bid response includes all required forms and documentation and that all are properly completed, signed, and notarized, where applicable. It is the bidders sole responsibility to complete and submit its bid via iSupplier to the corresponding RFQ prior the RFQ Bid Submission Deadline. NYCHA is not responsible for delays caused by technical difficulty or caused by any other occurrence. Only electronic bids submitted online via iSupplier will be accepted. For assistance regarding iSupplier please email NYCHA Procurement at procurement@nycha.nyc.gov. Please note that if NYCHA receives no responses to this RFQ, the bid submission deadline shall be automatically extended for seven (7) days. This does not limit NYCHA's right to extend the bid deadline for any other reason. Current Prevailing Wage Links are posted on iSupplier under the Quick Links Section of Sourcing Supplier.  The vendors are responsible for remaining informed of all updates to the Prevailing Wage Schedule.

New York
Due Oct 8, 2026View bid